To the Saga synthesis top

About Saga construction contract article (April 1, 2020 revision)

The last update date:
We publish Saga construction contract article.
 

Main contents of April 1, 2020 revision

 1. With revision of civil law, we changed about transfer of claims and obligations, contract nonconformity responsibility, termination of the agreement, guarantee of contract.

 2. With revision of Construction Industry Act, we added about prohibition of remarkably short term of works.

 3. We added about purpose expansion of advance.

 4. With revision of rate by notification based on law about prevention of delay in payment of government contract, we decided to change proportion of overdue interest to "2.6% a year" from "2.7% a year"

 

Main contents of April 1, 2019 revision

 We added supplementary provisions (and we contract after April 1, 2019 at the end of open contract period for contract after October 1, 2019).

 

Main contents of April 1, 2017 revision

  1. We decided person of order refused the performance of obligation by cancellation based on the bankruptcy law or to set of torture of person of order about objective impossibility and cancelation cost when it was about debt of person of order by reason that you should let leave. (2 relations of Article 46)
  2. With revision of rate by notification based on law (1949 law No. 256) about prevention of delay in payment of government contract, we decided to change proportion of overdue interest to "2.7% a year" from "2.8% a year". (Article 34, Article 45 and Article 49 relations)

 

Main contents of April 1, 2016 revision

  1. When owner admitted that we met constant requirements, it prescribed that we could not need permanent residence of the spot agent in article exceptionally and decided to entrust concrete requirements to the handling point. (Article 10 relations)
  2. With revision of rate by notification based on law (1949 law No. 256) about prevention of delay in payment of government contract, we decided to change proportion of overdue interest to "2.8% a year" from "2.9% a year". (Article 34, Article 45 and Article 49 relations)
  3. In the Antitrust Law after revision, umpire system to perform when cease-and-desist orders included dissatisfaction decided to review regulations pertaining to this with what was abolished. (2 relations of Article 46)

 

Main contents of April 1, 2014 revision

  1. With revision of rate by notification based on law (1949 law No. 256) about prevention of delay in payment of government contract, we decided to change proportion of overdue interest to "2.9% a year" from "3.0% a year". (Article 34, Article 45 and Article 49 relations)
  2. We decided to cancel contract unless construction object was completed when the other party of contract corresponded to gangs. (Article 46 relations)
  3. When it was in the other party of subcontract after the second subcontract and the other party of purchasing contract or other contracts of material, raw materials pertaining to the subcontract concerned, as case to cancel contract with person of order, gangs decided to add case that did not follow request of the termination of the agreement from owner concerned. (Article 46 relations)
  4. We decided to add regulations that could allot security (limited to active bond government bonds.) as a substitute for contract deposit and contract deposit to cancelation cost when gangs had termination based on exclusion article. (Article 46 relations)

 

The handling (April 19, 2013 mention) of arbitration statement of mutual agreement (addition) in May 13, 2013 ()

When person of order agrees to "agreeing that we refer to arbitration of Saga construction dispute examination committee about arbitration at the time of dispute occurrence and obey the arbitral award with owner" at the working contract conclusion, we fill out and seal, and we do attachment (we attach without doing contract and covered binding), and arbitration statement of mutual agreement, please submit the requirements to document of contract.
In addition, intention of person of order treats as thing which there is not about the agreement concerned at the working contract conclusion when there is not attachment of arbitration statement of mutual agreement or when the requirements are not listed.
In addition, we need decision of The Prefectural Assembly about applying for arbitration that dispute actually occurs and applies to Saga construction dispute examination committee for arbitration.

Attached file

 The handling accompanied with tax rate raise in April 1, 2019 consumption taxes

Page concerned

Various styles of guide of public works construction management

We relate to this page
Inquiry
(ID: 25911)
Saga prefectural government office (corporation number 1000020410004) 〒 840-8570  1-1-59, Jonai, Saga-shi   Tel: 0952-24-2111 (main)     
Copyright© 2016 Saga Prefecture.All Rights Reserved.

Saga prefectural government office (corporation number 1000020410004)

〒840-8570
1-1-59, Jonai, Saga-shi
Tel: 0952-24-2111 (main)
Copyright© 2016 Saga Prefecture.All Rights Reserved.